Terms & Conditions

01Services

Beach Construction and Demolition LLC provides residential and commercial roofing (installation, repair and replacement), general contracting and demolition services in and around Laurel, Montana. The exact scope of any job is defined in the written estimate, proposal or contract issued for that project.

02Estimates & Quotes

• Estimates are based on the information available at the time of inspection and are valid for 30 days unless stated otherwise.
• Hidden conditions discovered once work begins — such as rotted decking, structural damage, additional roofing layers, hazardous materials or code-required upgrades — may change the price. We will notify you before performing additional work.
• An estimate is not a binding contract until accepted in writing by both parties.

03Contracts & Change Orders

Each project is governed by a written agreement describing the scope, price, payment schedule and estimated timeline. Any change to the scope of work must be approved in writing (a "change order") and may affect the price and schedule. If anything in that project agreement conflicts with these Terms, the project agreement controls.

04Payments & Deposits

• A deposit may be required before work is scheduled or materials are ordered. The amount will be shown on your agreement.
• Remaining balances are due according to the payment schedule in your agreement, and in any case upon completion of the work unless otherwise agreed in writing.
• Late payments may be subject to late fees and collection costs to the extent permitted by Montana law.
• Under Montana law, contractors and suppliers who are not paid may have the right to file a construction lien against the property.

05Scheduling & Delays

Start and completion dates are estimates. Work may be delayed by weather, material shortages, permit or inspection timing, site conditions, or other events outside our reasonable control. Such delays do not make us liable for damages, but we will keep you informed and resume work as soon as practical.

06Customer Responsibilities

• Provide safe and reasonable access to the property and work area.
• Move or protect vehicles, outdoor furniture, valuables and fragile items near the work area.
• Disclose known hazards, including asbestos, lead, underground utilities, septic systems or structural concerns.
• Confirm that you own the property or are authorized to approve the work.
• Obtain any HOA approvals required for your property, unless we agree in writing to handle them.

07Permits & Codes

Unless the project agreement states otherwise, we will obtain the permits required for the work we perform and complete it in accordance with applicable building codes. Permit fees may be listed separately on your estimate.

08Demolition Work

• Utilities (gas, electric, water, sewer) must be disconnected or marked as required before demolition begins.
• Hazardous materials such as asbestos or lead paint may require testing and abatement by licensed specialists before demolition. Abatement is not included unless stated in your agreement.
• Some vibration, dust and noise are a normal part of demolition. We take reasonable care to protect adjacent property.
• Debris removal and site cleanup are included only as described in your agreement.

09Warranties

Workmanship warranty terms, if any, are stated in your project agreement. Manufacturer warranties on roofing materials are provided by the manufacturer and are subject to its terms. Warranties do not cover damage caused by severe weather, hail, fallen trees, fire, neglect, alterations by others, foot traffic, or failure to maintain the roof, gutters and ventilation.

10Limitation of Liability

To the fullest extent permitted by law, our total liability arising from any project is limited to the amount you paid for that project. We are not liable for indirect, incidental or consequential damages, including loss of use or loss of income. Nothing in these Terms limits liability that cannot be limited under Montana law.

11Website Use

• Content on this website is for general information only and does not constitute an offer or a binding quote.
• Images and graphics are illustrative and may not show actual completed projects.
• You may not copy, reproduce or misuse this website or its content without our written permission.
• We may update the website and these Terms at any time. The current version will always be posted on this page.

12Governing Law & Disputes

These Terms are governed by the laws of the State of Montana. If a dispute arises, both parties agree to first try to resolve it in good faith by direct discussion. Any legal action must be brought in the courts of Yellowstone County, Montana.

13Contact Us

Questions about these Terms can be sent to: